Back to Publications

Coronavirus & the Capital Works Management Framework – Guidance

Download Publication

Covid-19 and Capital Works Management Framework Article

On Tuesday, the Department of Public Expenditure and Reform issued updated guidance on procurement and contractual matters associated with the Covid-19 Response Measures (Coronavirus & the Capital Works Management Framework).

The purpose of the much-awaited guidance is to assist:

  • Contracting authorities that are required to procure essential professional services or works specifically related to Covid-19 response measures;
  • Contracting authorities that are currently engaged in a procurement process for works or services; and
  • Employers/Clients that are currently a party to a Public Works Contract (“PWC”) or Standard Conditions of Engagement.

Proceeding with tenders and entering into contracts

Many contracting authorities were unsure whether to proceed with tenders or whether to enter into contracts with successful tenderers.  In short, the guidance points out that contract opportunities are important in maintaining market confidence, but that this should be balanced with the sector’s capacity to respond.  If contracting authorities proceed with planned tenders it should consider longer tender deadlines, and selection criteria should be reviewed to ensure that it does not create a disproportionate barrier in these challenging times.  With respect to live tenders the advice is to extend the deadline by at least six weeks, which is to be reviewed two weeks prior to the deferred deadline (unless public health measures have eased in the meantime).  For tenders that have passed the deadline, the Office of Government Procurement is recommending that they should not be concluded until there is greater certainty unless there is a compelling reason to do so.

Dealing with delay under the Public Works Contracts

Many contracting authorities were also unsure as to how delay should be dealt with under the PWC for those projects deemed ‘non-essential’.  The note deals with this in detail.  I have summarised some key points below:

  • Employers should ensure that interim payments reflect progress up to the date that the site closed;
  • Delay is to be dealt with under Item 15 Schedule, Part 1k (PW CF 1-5);
  • The Contractor is to notify in accordance with 9.3 (PW CF 1-5);
  • Delay should be treated as having commenced on the date of site closure following the publication of Public Health Measures on 28 March 2020;
  • PWC does not provide entitlement to cover costs associated with delay for site closure;
  • In order to relieve financial pressure on Contractors, and as the Public Health Measures have been extended from (and including) 12 April 2020 to midnight on 4 May 2020 (“Applicable Period”), the Employer will make an ex gratia payment to the Contractor for the period that the site was closed during the Applicable Period (or portion thereof);
  • The ex gratia payment will be in respect of a portion of certain permissible items of the Contractor’s Preliminaries, unavoidably incurred and reasonable and vouched;
  • Prior to any such ex gratia payment being made, the Employer and the Contractor will record the amount of the ex gratia payment. This will be recorded in a supplemental agreement in accordance with the note;
  • The ex gratia payment should be included with the next scheduled interim payment following the recording of the agreement of the costs; and
  • Shorter interim payment periods may be considered where necessary.

Calculations for ‘ex gratia payments’

There is also a section on how the ‘ex gratia payment’ should be calculated, which is based on the Contractor’s preliminaries.  Notably, Contractors will get half of the calculated “supervision” element from the preliminaries.  This is not good news for contractors who did not price their preliminaries realistically.  No doubt there will also be some disagreements in relation to works which have been instructed to close and otherwise would have fallen under Item 3 Schedule, Part 1k.

If you have any questions on the above or any other related issue, feel free to contact Claire at Claire.Graydon@QuiggGolden.com.

The full publication from the Department of Public Expenditure and Reform can be found here: https://constructionprocurement.gov.ie/wp-content/uploads/CWMF-Update-1-to-Note-on-Covid-19-14-04-2020.pdf

Similar Publications

Published 13 August 2024

The Importance of a Contract Review

Read Publication

Published 5 August 2024

CCA 2013 – How can it help you to get paid as a contractor in Ireland?

Read Publication

Published 28 May 2024

Adjudication: Slips, trips and Fails.

Read Publication

Published 30 April 2024

Another win for adjudication in Ireland: €1.25m adjudication decision enforced.

Read Publication

Sign Up For Our Newsletter

Stay Updated on Our News & Events